Home
Français
Acts and Regulations
2023, c.15
- Construction Prompt Payment and Adjudication Act
Summary
Regulation
0
Full text
Detailled Table of Contents
Current to 1 January 2024
Construction Prompt Payment and Adjudication Act
1
DEFINITIONS, INTERPRETATION AND APPLICATION
1
Definitions
2
Interpretation of “services or materials”
3
Project agreements between the Crown or a local government and a special purpose entity
4
Application
5
This Act binds the Crown
2
PROMPT PAYMENT
6
Proper invoice – requirements
7
Giving proper invoices
8
Proper invoices not conditional on prior certification or approval
9
Revisions to proper invoices
10
Owner required to pay proper invoice
11
Notice of non-payment by owner
12
Payments by contractors to subcontractors
13
Payments by subcontractors to subcontractors
14
Reason for non-payment
15
Payments subject to requirement to retain amounts under the Construction Remedies Act
16
No effect on wages
17
Interest on late payments
3
INTERIM ADJUDICATION
18
Minister may designate Adjudicator Authority
19
Minister may act as interim Adjudicator Authority
20
Availability of adjudication
21
Adjudication procedures
22
Notice of adjudication
23
Time for commencing adjudication
24
Adjudication to address single dispute
25
Adjudication despite other proceedings
26
Adjudicator requirements
27
Duties and powers of adjudicators
28
Adjudicator’s determination
29
Compliance with determination
30
Interest on late payments
31
Suspension of work
32
Enforcement by the court
33
Effect of determination
34
Effect of determination – calculation of substantial performance
35
Costs of adjudication
36
Judicial review of determination
37
Immunity
38
Non-compellability
4
MISCELLANEOUS
39
Right to information
40
Disclosure of payments received
41
Damages
42
Court order
43
Giving or serving notices or other documents
44
Administration
45
Regulations
46
Commencement
0
Advanced search (includes point-in-time)
Consolidated Acts and Regulations
Acts
by title
by chapter
by department
Regulations
by regulation number
Annual Acts and Regulations
Acts
by year
Regulations
by year
Access Rules of Court
by rule number
Repealed Legislation (2011 onward)
Acts
by title
Selections
Show
Selections in current document
All selections in the collection
Selected elements
Delete all selections
Show selections
Cyberlex
Version 2.2.4.0